Welcome to Exotic Creations LLC, your trusted partner for high-quality Landscaping Solutions. By accessing or using our website, products, or services, you agree to comply with and be bound by the following terms and conditions. Please read them carefully before proceeding. If you do not agree with any part of these terms, please refrain from using our services.

Who We Serve

Exotic Creations LLC delivers high-performance Landscaping solutions to homeowners, contractors, developers, and businesses seeking reliable Landscaping.

Our Services

We offer a wide range of landscaping services, including but not limited to:

• Landscaping & Design
• Water Features
• Outdoor Living & Lighting
• Maintenance & Seasonal Services

All services are tailored to client needs with a focus on durability, craftsmanship, and visual appeal.

Use of Our Website

You may use our website for informational and non-commercial purposes. All content—including images, designs, logos, and text—is the intellectual property of Exotic Creations LLC and may not be copied, distributed, or reused without written consent.

Estimates & Proposals

Estimates provided through our website or during consultations are preliminary and based on the information available at the time. Final quotes may vary depending on site inspections, material choices, and scope of work. All proposals are valid for a limited period and may be subject to change based on market pricing or availability.

Scheduling & Completion

We make every effort to start and complete projects on time. However, schedules may shift due to weather, supply chain delays, permitting, or unexpected site conditions. We will always communicate proactively if timelines need adjustment.

Payment Terms

All projects require payment according to the terms specified in your contract or invoice. A deposit may be required to begin work. The remaining payments are due according to project milestones or upon completion. Late payments may result in service delays, penalties, or legal action.

Workmanship Warranty

Exotic Creations LLC stands behind the quality of its craftsmanship. We offer limited warranties on labor and materials, as detailed in your project contract. Warranties do not cover damage caused by natural disasters, wear and tear, misuse, or alterations by third parties.

Client Responsibilities

Clients agree to:

• Provide clear and safe access to the project site
• Secure all necessary permits unless otherwise agreed
• Disclose any known site conditions (e.g., underground utilities)
• Approve project plans and design elements in a timely manner

Failure to meet these responsibilities may result in additional costs or delays.

Intellectual Property

All designs, layouts, photos, and marketing content produced by Exotic Creations LLC remain our property unless otherwise agreed in writing. Unauthorized reproduction or reuse is strictly prohibited.

Third-Party Links

Our website may include links to third-party websites for your convenience. Exotic Creations LLC does not control these external sites and is not responsible for their content, accuracy, or privacy practices.

Limitation of Liability

Exotic Creations LLC is not liable for any indirect, incidental, or consequential damages resulting from your use of our website or services, except where liability is required by law. Our total liability for any claim related to our services shall not exceed the total amount paid for that service.

Updates to Terms

We may update these Terms periodically. Your continued use of our website or services after such changes indicates your acceptance of the updated Terms. We encourage you to review this page regularly.

Governing Law

These Terms are governed by the laws of the state where Exotic Creations LLC operates. Any disputes arising under these Terms shall be resolved in the courts of that jurisdiction.

Contact Us

If you have questions about these Terms & Conditions, feel free to reach out:

Exotic Creations LLC

Address: 11100 Bonita Beach Rd, Suite 103B, Bonita Springs, FL 34135

Email: Diane@exoticcreationsllc.com 

Phone No: +1 (239) 597-4414